Terms & Conditions

Welcome to KW Construction. These Terms and Conditions outline the rules and regulations for using our website and services. By accessing this website or engaging our services, you agree to comply with these terms.

1. Services

KW Construction provides a range of home improvement and construction services, as listed on our website. All services are subject to availability and a formal agreement or quotation.

2. Quotations and Pricing

All quotes provided are valid for 30 days unless stated otherwise.
Prices are subject to change if project specifications are altered after agreement.
Any unforeseen issues discovered during the project may affect pricing, but we will notify you in advance.

3. Booking & Payments

A deposit may be required before work begins.
Payment terms will be clearly stated in your quotation or contract.
Late payments may incur additional charges or result in project delays.

4. Client Responsibilities

Clients are expected to:

Provide accurate and complete information about the project
Ensure clear access to the property for scheduled work
Obtain any necessary permissions or approvals before work begins (unless agreed otherwise)

5. Project Timeline

We aim to complete all work within the estimated timeframe. However, delays due to weather, material shortages, or unforeseen circumstances may occur. We will communicate any delays promptly.

6. Cancellations and Refunds

Cancellations must be made in writing.
Deposits may be non-refundable if significant planning or material costs have already been incurred.
Refunds will be considered on a case-by-case basis, based on work completed and expenses incurred.

7. Liability

KW Construction is not liable for:

Damage caused by third-party contractors not engaged by us
Delays caused by events beyond our control (e.g. extreme weather, supply chain issues)
Existing structural issues or conditions unknown at the start of the project

8. Intellectual Property

All content on this website (text, images, logos) is the property of KW Construction. You may not copy, reproduce, or distribute any content without written permission.

9. Website Usage

By using our website, you agree not to:

Use the site for any unlawful purpose
Attempt to gain unauthorised access to systems or data
Distribute harmful or malicious content (e.g. viruses, spam)

10. Governing Law

These Terms are governed by and interpreted in accordance with the laws of England and Wales. Any disputes will be handled by the courts within this jurisdiction.